Skeeters.shop Dealer Order Terms and Conditions
Effective Date: September 11, 2026
These Dealer Order Terms and Conditions govern all dealer orders submitted to Skeeters.shop (“Seller,” “we,” “us,” or “our”). By submitting an order, approving artwork, checking the acceptance box, or accepting delivery, the dealer (“Dealer,” “you,” or “your”) agrees to these terms.
1. Dealer Eligibility
The Dealer Ordering Portal is intended exclusively for businesses approved by Skeeters.shop. Dealer access, pricing, credit privileges, and Net 14 terms may be approved, suspended, modified, or withdrawn at our discretion.
Dealer accounts may not be shared with unauthorized individuals or businesses. The Dealer is responsible for all orders submitted through its account.
2. Orders and Acceptance
Submitting an order does not guarantee acceptance. Orders become binding when accepted by Skeeters.shop through written confirmation, issuance of an invoice, preparation of artwork, or commencement of production.
We reserve the right to reject, cancel, or request clarification regarding incomplete, inaccurate, unlawful, inappropriate, or technically impractical orders.
3. Customization and Pricing
Listed dealer prices include:
- One approved sign background color.
- One vinyl lettering or design color.
- Standard layout and production.
- The size and quantity selected on the order form.
Additional colors, vinyl layers, detailed artwork, logo cleanup, specialty materials, unusual sizes, installation, expedited production, or other custom work may require additional charges and must be submitted through the Custom Order Portal.
Multiple signs using the same design and wording may be ordered together. Signs containing different wording, addresses, designs, or layouts must be submitted as separate orders unless otherwise approved in writing.
Prices are subject to change without notice. Accepted orders will be billed at the price confirmed for that order.
4. Artwork and Proof Approval
A digital proof may be provided before production. The Dealer is responsible for carefully reviewing all spelling, numbers, addresses, permit numbers, colors, dimensions, layout, and other details.
Production will not begin until required approval is received. Once artwork is approved, the Dealer accepts responsibility for the approved content. Skeeters.shop is not responsible for errors contained in artwork approved by the Dealer or its customer.
Changes requested after approval may result in additional design, material, and production charges. Significant changes may require a new order or revised quote.
Colors displayed on screens or printed proofs are approximate. Reflective vinyl and physical sign materials may appear brighter or different under varying lighting conditions.
5. Dealer-Supplied Artwork
The Dealer represents that it owns or has obtained permission to use every logo, photograph, trademark, design, slogan, typeface, or other item supplied for an order.
The Dealer authorizes Skeeters.shop to reproduce and modify submitted materials solely as necessary to design and manufacture the ordered products.
The Dealer agrees to defend, indemnify, and hold Skeeters.shop harmless from claims, losses, expenses, or damages resulting from the unauthorized use of Dealer-supplied content.
6. Payment Terms—Net 14
Approved Dealer accounts receive Net 14 payment terms unless different terms are stated on the invoice.
Full payment is due within fourteen calendar days of the invoice date. An invoice may be issued when an order is completed, shipped, delivered, or made available for pickup.
The Dealer may not delay payment because it has not collected payment from its customer. The Dealer remains responsible for the entire invoiced amount.
Past-due balances may result in:
- Suspension of Dealer Portal access.
- Suspension of Net 14 privileges.
- Requirement of payment before production.
- Delayed release of completed orders.
- Referral of the account for collection.
- Recovery of reasonable collection expenses when permitted by law.
Past-due balances may accrue a service charge of 1.5% per month or the maximum lawful rate, whichever is lower, beginning after the due date.
Disputed invoice amounts must be reported in writing within seven calendar days of the invoice date. Undisputed portions remain payable by the original due date.
7. Taxes
Dealer pricing does not include sales, use, excise, or similar taxes unless expressly stated.
Dealers claiming a resale exemption must provide a current and valid resale or exemption certificate before an order is processed without tax. The Dealer is responsible for taxes, penalties, or interest arising from an invalid or expired exemption.
8. Production Times
Production estimates begin after all required artwork, information, approvals, and deposits have been received.
Production and delivery dates are estimates unless Skeeters.shop expressly guarantees a date in writing. We are not responsible for delays caused by material availability, weather, carrier service, equipment failure, supplier delays, emergencies, government actions, labor interruptions, or circumstances beyond our reasonable control.
9. Delivery, Shipping and Pickup
Shipping, delivery, and installation charges are additional unless expressly included in the written quote or product listing.
The Dealer must inspect products promptly upon receipt. Visible shipping damage, shortages, or incorrect items must be reported in writing within three business days and supported by photographs of the product and packaging.
Failure to report visible problems within this period may limit our ability to submit a carrier claim or provide a remedy.
Risk of loss transfers to the Dealer upon delivery, pickup, or transfer to the shipping carrier, as applicable.
10. Custom Products, Cancellations and Returns
Because signs, decals, lettering, and related products are custom manufactured, orders cannot be canceled after artwork approval or production begins.
Custom products are nonreturnable and nonrefundable unless Skeeters.shop determines that the product contains a manufacturing defect or materially differs from the approved proof.
Dealer or customer preference changes, incorrect information supplied by the Dealer, installation errors, and approved artwork errors do not qualify as manufacturing defects.
If we authorize a return, the Dealer must follow the return instructions provided by Skeeters.shop. Unauthorized returns may be refused.
11. Limited Warranty
Any warranty applies only when expressly stated on the applicable product page, written quote, invoice, or separate warranty document.
Products expressly carrying a 10-year limited warranty are covered against qualifying material or manufacturing failures under normal intended outdoor use for ten years from the original completion date.
Warranty coverage does not include:
- Improper installation or mounting.
- Installation on unsuitable, contaminated, damaged, or improperly prepared surfaces.
- Damage caused by storms, flooding, ice, fire, impacts, accidents, vandalism, misuse, pressure washing, chemicals, abrasion, alterations, or neglect.
- Normal wear or reasonable changes in appearance.
- Damage caused by structures, brackets, fasteners, or mounting materials not supplied or approved by Skeeters.shop.
- Removal, reinstallation, transportation, or third-party labor unless approved in writing.
The Dealer must provide the original invoice and clear photographs when making a warranty claim. Our obligation is limited, at our discretion, to repairing or replacing the qualifying product or issuing an appropriate credit.
Replacement products do not restart the original warranty period unless stated in writing.
12. Installation
Installation is included only when expressly listed in the quote or invoice.
The Dealer or property owner is responsible for confirming installation permission, utility locations, structural suitability, property boundaries, landlord approval, marina rules, and applicable permits.
Skeeters.shop is not responsible for damage or product failure caused by installation performed by the Dealer, its customer, or another third party.
13. Codes and Regulatory Requirements
Our 911 dock signs are designed using information and guidance reviewed with Ameren Missouri, local fire departments, the Missouri State Highway Patrol–Water Patrol Division, and other emergency-service professionals.
Requirements may vary by location, property, utility, fire district, marina, or permitting authority. The Dealer and end customer remain responsible for confirming the current requirements applicable to each installation.
No statement on the Dealer Portal constitutes a guarantee that a particular sign, placement, mounting method, or installation will satisfy every local requirement.
14. Resale and Dealer Responsibilities
The Dealer is an independent business and is not an employee, agent, franchisee, partner, or legal representative of Skeeters.shop.
The Dealer may not make warranties, guarantees, safety claims, agency-approval claims, or product representations beyond the written information provided by Skeeters.shop.
The Dealer is responsible for its own customer pricing, tax collection, customer communication, installation commitments, and compliance with applicable laws.
15. Intellectual Property
All original layouts, proofs, templates, photographs, product descriptions, portal content, and artwork created by Skeeters.shop remain our intellectual property unless ownership is transferred through a separate written agreement.
Purchasing a finished product does not automatically transfer editable artwork, production files, templates, or reproduction rights.
The Dealer may use approved product photographs and marketing materials supplied by Skeeters.shop to promote authorized Skeeters.shop products. Those materials may not be altered in a misleading manner or used to manufacture competing products.
16. Limitation of Liability
To the fullest extent permitted by law, Skeeters.shop will not be liable for indirect, incidental, special, consequential, exemplary, or lost-profit damages arising from an order, product, delay, installation, or use of the Dealer Portal.
Our maximum liability relating to any order will not exceed the amount the Dealer actually paid for the product giving rise to the claim.
Nothing in these terms excludes liability that cannot legally be excluded.
17. Indemnification
The Dealer agrees to defend, indemnify, and hold harmless Skeeters.shop and its owners, employees, contractors, and suppliers from claims, damages, liabilities, costs, and reasonable legal expenses arising from:
- Dealer-supplied artwork or information.
- Unauthorized product claims or representations.
- Resale, installation, alteration, or misuse of products.
- Violation of laws, rules, permits, or third-party rights.
- The Dealer’s relationship or transaction with its customer.
18. Account Suspension or Termination
We may suspend or terminate Dealer Portal access, dealer pricing, or credit privileges for past-due balances, misuse of the portal, unauthorized account sharing, fraudulent activity, repeated order problems, violation of these terms, or conduct harmful to Skeeters.shop.
Termination does not eliminate the Dealer’s obligation to pay outstanding balances.
19. Privacy and Electronic Communications
The Dealer consents to receiving order confirmations, proofs, invoices, payment notices, one-time access codes, and account communications electronically.
The Dealer is responsible for maintaining a current email address and securing its account access.
Electronic acceptance of these terms, including checking an acceptance box or submitting an order, will have the same effect as a handwritten signature to the extent permitted by law.
20. Governing Law and Disputes
These terms and all Dealer orders are governed by the laws of the State of Missouri, without regard to conflict-of-law principles.
Before filing a legal action, the parties agree to make a good-faith effort to resolve the dispute through direct communication.
Any legal proceeding must be filed in a court of competent jurisdiction located in the Missouri county where Skeeters.shop maintains its principal place of business, unless applicable law requires otherwise.
21. Changes to These Terms
We may update these terms periodically. The terms in effect when an order is submitted will govern that order unless both parties agree otherwise in writing.
22. Entire Agreement and Severability
These terms, the accepted order, approved artwork, invoice, written quote, and applicable warranty policy constitute the agreement between Skeeters.shop and the Dealer.
If any provision is found unenforceable, the remaining provisions will continue in effect. Failure to enforce a provision does not waive our right to enforce it later.
If a written quote or invoice conflicts with these general terms, the specific written quote or invoice will control for that order.
23. Contact Information
Skeeters.shop Lake Ozark, Missouri Phone: 217-430-8884 Email: mike@skeeters.shop Website: https://skeeters.shop
Dealer Acceptance
By checking the acceptance box and submitting an order, I confirm that:
- I am authorized to place orders on behalf of the Dealer.
- I have reviewed the order information for accuracy.
- I agree to Skeeters.shop’s Dealer Order Terms and Conditions.
- I understand that approved custom products are generally noncancelable and nonreturnable.
- I accept Net 14 payment terms and agree to pay invoices when due.
Required checkbox wording:
☐ I have read and agree to the Skeeters.shop Dealer Order Terms and Conditions, including the Net 14 payment terms, artwork-approval requirements, and custom-product return policy.